BERNHEIM, KAHN & LOZANO, ARCHITECTS, LTD., A Professional Corporation, Claimant, v. THE STATE OF ILLINOIS, Respondent.
Case summary
Claimant sought damages for delays in the Addison Specialized Living Center construction project caused by the Capital Development Board. The court awarded $26,377.00 based on a joint stipulation of the parties.
AI-generated summary from the opinion text — may contain errors. The opinion text and PDF above are the official record.
Headnotes
- TYRONE C. FAHNER, Attorney General (KATHLEEN ~ ' BRIEN Assistant , Attorney General, of counsel), for Respondent. ~ T l PULATI o N s ~ r C h i t e C t uservicesra~ delay attributable to State-claim allowed. On basis of stipulation of parties, award was granted for damages suffered by architect due to delays attributable to State on construction project.
This cause coming on to be heard on the joint stipulation of the parties and the Court being fully advised in the premises; This claim arises out of services performed by Claimant for the Capital Development Board in the Addison Specialized Living Center construction project during the years 1976,1977,1978,1979 and 1980.
Claimant performed its services in accordance with its contract with the Capital Development Board on this project. Claimant was damaged as a result of delays in the project which were not attributable to any act of the Claimant, but were attributable to acts or omissions of the Capital Development Board.
The Respondent has investigated the damages herein claimed, and both parties agree that the Claimant was damaged in the amount of $26,377.00.
It is hereby ordered that the Claimant be awarded, in full satisfaction of any and all claims arising out of the contract which is the subject of this claim, the sum of [*379] $26,377.00 (twenty six thousand, three hundred seventyseven dollars and no cents).